Thesis: Make a Contract

Pages: 1 (300 words)  ·  Bibliography Sources: 0  ·  Level: College Senior  ·  Topic: Architecture  ·  Buy This Paper

Construction Contract

The following agreement is entered into by Harry Holmes (hereinafter

"Homeowner") and Chris Conrad (hereinafter "Contractor") and constitutes the entire understanding between Homeowner and Contractor of the services provided by Contractor to remodel Homeowner's kitchen.

Homeowner will furnish $2,500 as a nonrefundable deposit on the date of this agreement representing one-half the total agreed amount of $5,000 for the complete project, the balance of which is payable on the date that the project is completed by Contractor. Contractor agrees to complete the project on or before June 1, 2009 and further represents that time is of the essence and that failure to complete the project on that date will entitle Homeowner to a negotiated refund of $100 per day up to the total amount of the project for any delay not caused by the Homeowner or by circumstances commonly referred to as "acts of God." Homeowner agrees to… [END OF PREVIEW]

Contract Theories Term Paper


Contract Issues in "Proof of Life Essay


Contract Endzone Inc. Has Sued Maverick Sports Essay


Contracting Officer Research Paper


Contract Law Legal Ethical and Social Issues in Computing Essay


View 1,000+ other related papers  >>

Cite This Thesis:

APA Format

Make a Contract.  (2009, April 4).  Retrieved August 20, 2019, from https://www.essaytown.com/subjects/paper/make-contract/72290

MLA Format

"Make a Contract."  4 April 2009.  Web.  20 August 2019. <https://www.essaytown.com/subjects/paper/make-contract/72290>.

Chicago Format

"Make a Contract."  Essaytown.com.  April 4, 2009.  Accessed August 20, 2019.
https://www.essaytown.com/subjects/paper/make-contract/72290.